Defendant/counterclaim plaintiff Xtreme Concrete's counterclaim for delay damages was properly dismissed as barred by the subcontract's no damages for delay provision. Contrary to Xtreme's assertion that it seeks damages for delays not within the parties' contemplation at the time the subcontract was entered into, the cause of the subject delay—incomplete drawings —was expressly mentioned in the contract as a possibility and was therefore, "by definition, `contemplated...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.
