Plaintiff has met its burden of pointing to evidence raising triable issues of fact as to whether WDF engaged in intentional misconduct by willfully interfering with plaintiff's timely performance of its subcontracts. It is undisputed that the subject projects suffered extensive delays when a high-voltage cable owned by the Long Island Power Authority (the LIPA cable) was discovered running alongside the subway line on which the work was being performed. Subsequent to this...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.
