Plaintiff, an HVAC subcontractor hired to perform work on a construction project on Columbia University's Manhattanville campus, filed a complaint alleging, inter alia, that defendants delayed the project causing them damages. To defeat an enforceable no delay damages clause in the subcontract, plaintiff made conclusory allegations to try to apply one of the exceptions set forth in Corinno Civetta Constr. Corp. v City of New York (
Welcome to the leading source of independent legal reporting
Let's get started
Sign on now to see your case.
Or view more than 10 million decisions and orders.
WDF, INC. v. THE TRUSTEES OF COLUMBIA UNIV. IN THE CITY OF N.Y.
8729N, 651250/16.
170 A.D.3d 518 (2019)
96 N.Y.S.3d 42
2019 NY Slip Op 01850
WDF, Inc., Appellant, v. The Trustees of Columbia University in the City of New York et al., Respondents.
Appellate Division of the Supreme Court of New York, First Department.https://leagle.com/images/logo.png
Decided March 14, 2019.
Decided March 14, 2019.
Appellate Division of the Supreme Court of New York, First Department.
Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.
Cited Cases
- No Cases Found
Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.