1. Home
  2. Browse Decisions
  3. A.D.3d
  4. 145 A.D.3d
  5. 145 A.D.3d 523 (2016)
 

MATTER OF LAWS CONSTRUCTION CORP. v. CONTRACT DISPUTE RESOLUTION BD.

154730/15, 2448, 159473/14, 2447.

145 A.D.3d 523 (2016)

2016 NY Slip Op 08326

45 N.Y.S.3d 385

In the Matter of LAWS CONSTRUCTION CORP., Appellant, v. CONTRACT DISPUTE RESOLUTION BOARD et al., Respondents. In the Matter of LAWS CONSTRUCTION CORP., Appellant, v. CONTRACT DISPUTE RESOLUTION BOARD et al., Respondents.

Appellate Division of the Supreme Court of New York, First Department.

Decided December 13, 2016.

CDRB's determinations that petitioner waived its claims had a rational basis (see generally Matter of Beck-Nichols v Bianco, 20 N.Y.3d 540, 559 [2013]). The contract governing the construction project required any request for an extension of time filed by petitioner to include a statement, "in detail," that petitioner "waives all claims except for those delineated in the application, and the particulars of any claims which [petitioner...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases