Stein, J.
Plaintiff was hired as a subcontractor by defendant U.W. Marx, Inc. (hereinafter defendant) to install steel reinforcement on a fast-track construction project pursuant to a written subcontract executed by the parties. It is undisputed that plaintiff's contemplated start date was delayed for a variety of reasons, all unrelated to plaintiff.
Shortly after plaintiff finally began its work with an initial crew of six workers and an anticipated maximum...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.
