LAW CO., INC. v. MOHAWK CONST. AND SUPPLY CO.

No. 08-3076.

577 F.3d 1164 (2009)

The LAW COMPANY, INC., a Kansas corporation, Plaintiff/Counter-Defendant-Appellee, v. MOHAWK CONSTRUCTION AND SUPPLY COMPANY, INC., a Pennsylvania corporation, Defendant/Counter-Claimant-Appellant.

United States Court of Appeals, Tenth Circuit.

August 17, 2009.


Attorney(s) appearing for the Case

David E. White (Joshua C. Dickinson and Barry L. Pickens, Spencer Fane Britt & Browne LLP; and Richard W. Saxe, Jr., Babst, Calland, Clements & Zomnir, P.C., with him on briefs), Babst, Calland, Clements & Zomnir, P.C., Pittsburgh, PA, for Defendant/Counter-Claimant-Appellant.

Ron Campbell (Lyndon W. Vix with him on the briefs), Fleeson, Gooing, Coulson & Kitch, L.L.C., Wichita, KS, for Plaintiff/Counter-Defendant-Appellee.

Before BRISCOE, SEYMOUR, and LUCERO, Circuit Judges.


LUCERO, Circuit Judge.

The Law Company, Inc. ("Law"), a general contractor, sought a declaratory judgment that one of its subcontractors, Mohawk Construction and Supply Company, Inc. ("Mohawk"), is barred from collecting delay damages under the parties' subcontract. Mohawk counterclaimed for breach of contract. On summary judgment, the district court refused to consider two affidavits and numerous documents submitted by Mohawk and declined to address several of Mohawk...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases