CARPINELLO, J.
At issue is an $185,000, plus interest, damage award to Tougher Industries, Inc., a subcontractor of claimant on a correctional facility construction project. Damages were awarded to Tougher, which had a liquidating agreement with claimant, as a result of defendant's failure to properly coordinate the project. Defendant does not take issue with the substantive finding that it caused delays in this project; rather, on appeal, it claims that a contractual...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.