1. Home
  2. Browse Decisions
  3. A.D.3d
  4. 6 A.D.3d
  5. 6 A.D.3d 228 (2004)
 

BOVIS LEND LEASE LMB INC. v. GCT VENTURE, INC.

6 A.D.3d 228 (2004)

775 N.Y.S.2d 259

BOVIS LEND LEASE LMB INC., Formerly Known as LEHRER McGOVERN BOVIS, INC., Respondent, v. GCT VENTURE, INC., et al., Appellants, et al., Defendants.

Appellate Division of the Supreme Court of the State of New York, First Department.

April 13, 2004.

This is a contract dispute over costs added in connection with the restoration and renovation of New York's Grand Central Terminal. The delays and additional work at issue in the fourth cause of action involve improvements to the terminal's retail space, performed by plaintiff's electrical subcontractor. Both the general contract and the electrical subcontract contain no-damages-for-delay clauses.

While clauses in construction contracts exculpating parties

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases