1. Home
  2. Browse Decisions
  3. P.3d
  4. 67 P.3d
  5. 67 P.3d 328 (2003)
 

CALIFORNIA COMMERCIAL v. AMEDEO VEGAS I

No. 38042.

67 P.3d 328 (2003)

CALIFORNIA COMMERCIAL ENTERPRISES, d/b/a Commercial Enterprises, Appellant, v. AMEDEO VEGAS I, INC., A Delaware Corporation, Respondent.

Supreme Court of Nevada.

April 29, 2003.

Attorney(s) appearing for the Case

Morse & Mowbray and Christopher H. Byrd and John H. Mowbray, Las Vegas; Hunt, Ortmann, Blasco, Palffy & Rossell and Laurence P. Lubka, Pasadena, California, for Appellant.

Hale Lane Peek Dennison and Howard and Shannon M. Bryant, Steven B. Lane, and Torry R. Somers, Las Vegas; Bryan Cave LLP and Christopher L. Dueringer and Sheldon Eisenberg, Santa Monica, California, for Respondent.

Before AGOSTI, C.J., ROSE and GIBBONS, JJ.

OPINION

PER CURIAM.

In this appeal, we must determine if a mechanic's lien may be used to recover delay and disruption damages when a contract exists between the parties. California Commercial Enterprises (Commercial), a framing and drywall subcontractor, contracted with R.D. Olson to perform work for a development owned by Amedeo Vegas I, Inc. (Amedeo). After Commercial finished its work, which was allegedly delayed for sixteen months by Amedeo,...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases