1. Home
  2. Browse Decisions
  3. F.3d
  4. 243 F.3d
  5. 243 F.3d 25 (2001)
 

NORTHEAST DRILLING v. INNER SPACE SERVICES

No. 00-1684.

243 F.3d 25 (2001)

NORTHEAST DRILLING, INC., Plaintiff, Appellee, v. INNER SPACE SERVICES, INC.; National Grange Mutual Insurance Company, Defendants, Appellants, v. Ranger Insurance Company, Inc., Counterclaim Defendant, Appellee.

United States Court of Appeals, First Circuit.

Decided March 16, 2001.

Attorney(s) appearing for the Case

Richard L. Neumeier, with whom Timothy J. van der Veen and McDonough, Hacking & Neumeier, LLP, were on brief, for appellants.

Deirdre M. Smith, with whom Jerrol A. Crouter and Drummond Woodsum & MacMahon, were on brief, for appellees.

Before SELYA, Circuit Judge, STAHL, Circuit Judge, and LISI, District Judge.

STAHL, Circuit Judge.

During the construction of a shipbuilding facility in Bath, Maine, a series of events, primarily attributable to the caprices of nature, delayed the schedule, forcing significant alterations to the work plan and ultimately making the project more expensive than had been anticipated. These events led to a dispute between the project's dredging subcontractor, Inner Space Services, Inc. ("ISSI"), and the drilling and blasting subcontractor it had...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases