1. Home
  2. Browse Decisions
  3. So.2d
  4. 774 So.2d
  5. 774 So.2d 50 (2000)
 

TRIPLE R PAVING, INC. v. BROWARD COUNTY

Nos. 4D99-3609, 4D99-3610.

774 So.2d 50 (2000)

TRIPLE R PAVING, INC., a Florida corporation, Appellant, v. BROWARD COUNTY, a political subdivision of the state of Florida, Appellee. Frederic R. Harris, Inc., Appellant, v. Triple R. Paving, Inc., a Florida corporation, Appellee.

District Court of Appeal of Florida, Fourth District.

Rehearing Denied January 12, 2001.

Attorney(s) appearing for the Case

Joseph W. Lawrence, II and Frederick J. Springer of Vezina, Lawrence & Piscitelli, P.A., Fort Lauderdale, for Appellant/Appellee Triple R Paving, Inc.

David B. Mankuta and Margaret Z. Villella of Atkinson, Diner, Stone, Mankuta & Ploucha, P.A., Hollywood, for Appellant Frederic R. Harris, Inc.

Edward A. Dion, County Attorney; Andrew J. Meyers, Chief Appellate Counsel; and Tamara M. Scrudders, Assistant County Attorney, Fort Lauderdale, for Appellee Broward County.

STONE, J.

Triple R Paving, Inc. ("Triple R"), plaintiff below, and Frederic R. Harris, Inc. ("Harris"), third-party defendant, appeal from a judgment awarding damages to Triple R resulting from construction delays in the performance of its road construction contract with Broward County, Harris' indemnitee. The appeals have been consolidated for review.

Triple R successfully bid on a road construction contract, the design for which was prepared by Harris. The...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases