Order unanimously reversed on the law without costs, motion granted and amended complaint dismissed.
Memorandum:
Supreme Court erred in denying defendants' motion for summary judgment dismissing the amended complaint. Plaintiff subcontractor commenced this action seeking damages for delays allegedly caused by defendant LaBarge Brothers Company, Inc. (LaBarge), the general contractor. The subcontract bars plaintiff from seeking damages for those delays, and...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.