1. Home
  2. Browse Decisions
  3. A.D.2d
  4. 260 A.D.2d
  5. 260 A.D.2d 253 (1999)
 

MATTER OF TEDDY GIANNOPULOS GENERAL CONTRACTORS, INC. v. NEW YORK CITY HOUSING AUTHORITY

260 A.D.2d 253 (1999)

688 N.Y.S.2d 536

In the Matter of TEDDY GIANNOPULOS GENERAL CONTRACTORS, INC., Appellant, v. NEW YORK CITY HOUSING AUTHORITY, Respondent.

Appellate Division of the Supreme Court of the State of New York, First Department.

Decided April 20, 1999.

Petitioner fails to present proof that any delay in replacing the defaulting electrical contractor was "grossly negligent conduct" defeating the no-damage-for-delay clause in the parties' contract (see, Corinno Civetta Constr. Corp. v City of New York, 67 N.Y.2d 297, 309). In fact, all of the delays petitioner points to were of a type contemplated by the contract, which provided that there would be no increased payments. Hence, the...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases