MAIN ELEC., LTD. v. PRINTZ SERVICES CORP.

No. 97SC601.

980 P.2d 522 (1999)

MAIN ELECTRIC, LTD.; and Connie J. Sullivan-Brown d/b/a C.J. Masonry, Petitioners, v. PRINTZ SERVICES CORPORATION, a Colorado corporation, d/b/a T.L. Printz Constructors, Respondent.

Supreme Court of Colorado, En Banc.

March 15, 1999.


Attorney(s) appearing for the Case

Warren, Mundt & Martin, P.C., Robert B. Warren, Colorado Springs, Colorado, Attorneys for Petitioner Main Electric, Ltd.

Hendricks, Hendricks & Shakes, P.C., David L. Shakes, Davyne A. Ryals, Colorado Springs, Colorado, Attorneys for Petitioner Connie J. Sullivan-Brown d/b/a C.J. Masonry.

Holland & Hart, LLP

David S. Prince, Elaine H. Turner, Colorado Springs, Colorado, Attorneys for Respondent.

Hall & Evans, L.L.C., Jeffrey B. Stalder, Denver, Colorado, Attorneys for Amicus Curiae R.N. Robinson & Son, Inc.

Woodrow & Gruskin, Professional Corporation, Mark D. Gruskin, Denise LaBier Pilkington, Denver, Colorado, Attorneys for Amicus Curiae American Subcontractors Association.


BENDER, Justice.

In this case we interpret the payment provisions of a construction contract to require a general contractor to pay a subcontractor even though the owner has failed to pay the general contractor. This provision is referred to as a "pay-when-paid" clause. We hold that the "when" of this clause is not a contingency, but rather means that payment may be delayed. We decline to find that this clause is a "pay-if-paid" clause that excuses the general contractor...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases