Defendant Lehr, the general contractor on a renovation contract for premises occupied by defendant Rose Associates, should not have been held liable for delay damages allegedly sustained by plaintiff Phoenix, the electrical subcontractor, as a result of labor disruptions caused by Rose personnel or by design and engineering changes ordered by Rose's architect and engineer after commencement of the project. "[A]bsent a contractual commitment to the contrary, a prime contractor...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.