This action arises out of a contract between plaintiff Huff Enterprises, Inc. and defendant Triborough Bridge and Tunnel Authority for construction of office facilities on Randalls Island. Under the terms of the agreement, work was to begin in April of 1986 and be completed by October 30, 1987, but substantial completion did not occur until December of 1988, and the project was fully completed in 1989. The delay was largely attributable to defendant's revision of the construction...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.