1. Home
  2. Browse Decisions
  3. F.3d
  4. 12 F.3d
  5. 12 F.3d 1053 (1993)
 

INTERSTATE GENERAL GOVERNMENT CONTRACTORS v. WEST

No. 92-1430.

12 F.3d 1053 (1993)

INTERSTATE GENERAL GOVERNMENT CONTRACTORS, INC., Appellant, v. Togo WEST, Secretary of the Army, Appellee.

United States Court of Appeals, Federal Circuit.

Precedential Opinion Issued December 6, 1993.

Attorney(s) appearing for the Case

Glen W. Clark, Jr., Palmer, Howard and Clark, Austell, GA, argued for appellant.

Thomas A. Dinackus, Atty., Commercial Litigation Branch, Dept. of Justice, Washington, DC, argued for appellee. With him on the brief were Stuart M. Gerson, Asst. Atty. Gen., David M. Cohen, Director and James M. Kinsella, Asst. Director. Also on the brief was Major Robert Duecaster, Contract Appeals Div., Army Legal Services Agency, of counsel.

Before MICHEL, RADER, Circuit Judges, and COHN, District Judge.

MICHEL, Circuit Judge.

Interstate General Government Contractors, Inc. (IGGC) appeals from a decision of the Armed Services Board of Contract Appeals (Board) denying IGGC's claim for an equitable adjustment for alleged unabsorbed home office overhead caused by the government's delay in issuing a notice to proceed (NTP) on a contract to renovate army barracks. Interstate Gen. Gov't Contractors, Inc., ASBCA No. 43369, 92-2 BCA ¶ 24,956, 1992 WL 59384 (March...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases