1. Home
  2. Browse Decisions
  3. So.2d
  4. 528 So.2d
  5. 528 So.2d 72 (1988)
 

H. PEPPER & ASSOC., INC. v. HARDRIVES CO., INC.

No. 87-0426.

528 So.2d 72 (1988)

HARRY PEPPER & ASSOCIATES, INC., a Florida Corporation, Appellant, v. HARDRIVES COMPANY, INC., a Florida Corporation, Appellee.

District Court of Appeal of Florida, Fourth District.

July 6, 1988.

Attorney(s) appearing for the Case

Philip T. Weinstein of Weinstein & Garvin, P.A., Miami, for appellant.

Kenneth G. Stevens, Fort Lauderdale, for appellee.

LETTS, Judge.

This controversy evolves from a trial judge's ruling that a paving subcontractor was justified in walking off the site of a plant construction project and canceling the obligation to pave it. The general contractor argues that the subcontractor was bound by the language of the contract between them which provided that the latter's only remedy was to get an extension of time and that cancellation was not permitted under the contract. We agree with the...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases