1. Home
  2. Browse Decisions
  3. So.2d
  4. 504 So.2d
  5. 504 So.2d 1374 (1987)
 

BOARD OF REGENTS v. STINSON-HEAD, INC.

No. 4-86-2129.

504 So.2d 1374 (1987)

BOARD OF REGENTS of the State of Florida, Appellant, v. STINSON-HEAD, INC., Appellee.

District Court of Appeal of Florida, Fourth District.

April 8, 1987.

Attorney(s) appearing for the Case

Gregg A. Gleason, Tallahassee, for appellant.

J. Michael Burman and Gary Russo of Slawson & Burman, North Palm Beach, for appellee.

DOWNEY, Judge.

Appellant, Board of Regents of the State of Florida (Board), and appellee, Stinson-Head, Inc. (Stinson), entered into a construction agreement whereby Stinson would build an addition to the library on the campus of Florida Atlantic University. After work had begun on the project, Stinson made a claim for an additional $585,154.89 and time extension of 145 days due to incompatibilities in the specifications and drawings. The project architects denied...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases