1. Home
  2. Browse Decisions
  3. So.2d
  4. 425 So.2d
  5. 425 So.2d 632 (1983)
 

CONCRETE SYSTEMS, INC. v. FLORIDA ELECTRIC COMPANY OF ORLANDO

No. 82-625.

425 So.2d 632 (1983)

CONCRETE SYSTEMS, INC., a Florida Corporation, Appellant, v. FLORIDA ELECTRIC COMPANY OF ORLANDO, a Florida Corporation, Appellee.

District Court of Appeal of Florida, Second District.

January 21, 1983.

Attorney(s) appearing for the Case

Glenn T. Shelby of Law Offices of James S. Welch, Lakeland, for appellant.

David L. Evans of Mateer, Harbert, Bechtel & Phalin, P.A., Orlando, for appellee.

GRIMES, Judge.

This case involves a dispute between a contractor and an electrical subcontractor on a school construction project.

Concrete Systems, Inc., entered into a contract with Highlands County School Board to perform certain school construction work. The contract called for a completion date of August 23, 1978, and contained a $250 per day liquidated damage clause for delay in finishing the project. The work was actually completed on November 7, 1978...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases