Plaintiff and the New York City Transit Authority, acting as defendant's agent, entered into a contract for improvement of the Queens Village Bus Depot. The contract specified August 6, 1973 as the completion date. Because of the initial unavailability of the job site and delays caused by other subcontractors, the completion date was extended, at plaintiff's request, to January 10, 1975. A final certificate of completion was filed May 19, 1976. Plaintiff contends that by...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.