1. Home
  2. Browse Decisions
  3. S.E.2d
  4. 288 S.E.2d
  5. 288 S.E.2d 437 (1982)
 

PEBBLE BLDG. CO. v. G. J. HOPKINS, INC.

Record No. 801946.

288 S.E.2d 437 (1982)

The PEBBLE BUILDING COMPANY, et al. v. G. J. HOPKINS, INCORPORATED.

Supreme Court of Virginia.

March 12, 1982.

Attorney(s) appearing for the Case

S. D. Roberts Moore, Roanoke (Eugene E. Derryberry; Gentry, Locke, Rakes & Moore, Roanoke, on brief), for appellants.

Charles H. Osterhoudt, Roanoke (Michael J. Aheron; Osterhoudt, Ferguson, Natt, Aheron & Agee, P.C., Roanoke, on brief), for appellee.

Before CARRICO, C. J., COCHRAN, POFF, COMPTON, THOMPSON and STEPHENSON, JJ., and HARRISON, Retired Justice.

PER CURIAM.

In this construction contract case, we decide whether the evidence is sufficient to sustain an award of delay damages in favor of a subcontractor against the general contractor.

The Pebble Building Company, a defendant below, was the prime contractor for construction of a municipal parking facility in the City of Roanoke. The contract, as amended by change orders, required completion of the project in May of 1977, within 638 calendar days. In August...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases