1. Home
  2. Browse Decisions
  3. N.W.2d
  4. 323 N.W.2d
  5. 323 N.W.2d 214 (1982)
 

I.G.L. RACQUET CLUB v. MIDSTATES BUILDERS

No. 66495.

323 N.W.2d 214 (1982)

I. G. L. RACQUET CLUB, Plaintiff-Appellant, v. MIDSTATES BUILDERS, INC., Defendant-Appellee, MIDSTATES BUILDERS, INC., Counterclaimant-Appellee, v. I. G. L. RACQUET CLUB, Defendant to Counterclaimant-Appellant, MIDSTATES BUILDERS, INC., Cross-Petition Plaintiff-Appellee, v. BROOKS MOTEL and Brooks Country Club, Cross-Petition Defendants-Appellants.

Supreme Court of Iowa.

August 25, 1982.

Attorney(s) appearing for the Case

Larry A. Stoller of Stoller & Larson, Spirit Lake, for appellants.

Richard Meyer of Fitzgibbons Brothers, Estherville, for appellee.

Considered by REYNOLDSON, C. J., and LeGRAND, UHLENHOPP, HARRIS, and LARSON, JJ.

HARRIS, Justice.

By a series of pretrial and trial rulings a litigant was prevented from presenting a claim in a dispute which arose from a contract to build a recreational facility. The owner (plaintiff) sought damages by reason of a delay in completion of construction.

Plaintiff1 asserted the contract was "partly written and partly oral." The writing made no mention of completion date. Plaintiff sought to show that, under the...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases