In this action by a subcontractor against a general contractor, the trial court, in a bench trial, correctly held that the suspension of work by plaintiff was precipitated by defendant's failure to make payment to it and plaintiff's resultant lack of funds. Accordingly, it found that plaintiff had not breached the contract, and, by consequence, plaintiff was entitled to recover on its claim and that defendant's counterclaim, bottomed on an alleged breach of the contract,...
Let's get started
Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.
- Updated daily.
- Uncompromising quality.
- Complete, Accurate, Current.