1. Home
  2. Browse Decisions
  3. So.2d
  4. 408 So.2d
  5. 408 So.2d 1158 (1981)
 

SOUTHBEND CONTRACTORS, INC. v. PARISH OF JEFFERSON

No. 12187.

408 So.2d 1158 (1981)

SOUTHBEND CONTRACTORS, INC. v. PARISH OF JEFFERSON, Jefferson Parish Council and East Jefferson Water District No. 1.

Court of Appeal of Louisiana, Fourth Circuit.

Rehearing Denied February 19, 1982.

Attorney(s) appearing for the Case

Walter B. Stuart, IV and Gerald J. Slattery, Jr., Singer, Hutner, Levine, Seeman & Stuart, New Orleans, for Southbend Contractors, Inc. plaintiff-appellant.

Joseph A. Conino, Asst. Parish Atty., Gretna, for Parish of Jefferson, Jefferson Parish Council and East Jefferson Water Dist. No. 1 defendants-appellees.

Before BOUTALL, CHEHARDY and KLIEBERT, JJ.

BOUTALL, Judge.

A contractor sues for extra work allegedly done pursuant to a construction contract and the owner reconvenes for liquidated damages for delay in completion of the contract. From a judgment granting only a portion of the main demand and awarding liquidated damages on the reconventional demand, the contractor has appealed. We affirm.

Southbend Contractors, Inc., entered into a contract with the Parish of Jefferson to repair, replace and modify...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases