1. Home
  2. Browse Decisions
  3. So.2d
  4. 407 So.2d
  5. 407 So.2d 947 (1981)
 

AM. FID. FIRE INS. CO. v. WOODY'S ELEC. SERV.

No. 80-2198.

407 So.2d 947 (1981)

AMERICAN FIDELITY FIRE INSURANCE COMPANY, Appellant, v. WOODY'S ELECTRIC SERVICE, INC., Appellee.

District Court of Appeal of Florida, Third District.

Rehearing Denied January 11, 1982.

Attorney(s) appearing for the Case

James F. Comander, Miami, for appellant.

Tittle, Tittle & Beckmeyer, Tavernier, and Gus H. Crowell, Miami, for appellee.

Before BARKDULL, BASKIN and PEARSON, DANIEL, JJ.

DANIEL S. PEARSON, Judge.

American Fidelity Fire Insurance Company, the plaintiff below, was a subrogee of Design Construction Corporation, a general contractor. American Fidelity, having paid delay damages to a school board under a performance bond posted for Design, sought to recover these damages from Woody's Electric Service, Inc. The gist of its complaint was that Design was delayed in completing the school board construction project because of delay by Woody...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases