1. Home
  2. Browse Decisions
  3. N.J.
  4. 173 N.J.
  5. 173 N.J. Super. 486 (1980)
 

SASSO CONTRACTING CO. v. STATE

173 N.J. Super. 486 (1980)

414 A.2d 603

SASSO CONTRACTING CO., INC., PLAINTIFF-RESPONDENT, v. STATE OF NEW JERSEY, DEFENDANT-APPELLANT.

Superior Court of New Jersey, Appellate Division.

Decided May 8, 1980.

Attorney(s) appearing for the Case

Jerry Fischer, Deputy Attorney General, argued the cause for appellant (John J. Degnan, Attorney General of New Jersey, attorney; Erminie L. Conley, Assistant Attorney General, of counsel).

Theodore W. Geiser argued the cause for respondent (Connell, Foley & Geiser, attorneys; John F. Neary and Thomas S. Cosma on the brief).

Before Judges LORA, ANTELL and PRESSLER.

The opinion of the court was delivered by ANTELL, J.A.D.

After allowing a credit of $26,827.80 for defects and $1,700 liquidated damages for delayed performance, the Law Division entered judgment in the amount of $118,788.28 in favor of plaintiff and against defendant. The suit arose from a contract for the installation of longitudinal drains along a section of Route 78, and the judgment reflects losses incurred because of inaccuracies in the advertised plans and...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases