1. Home
  2. Browse Decisions
  3. A.2d
  4. 402 A.2d
  5. 402 A.2d 1222 (1979)
 

JOHN McSHAIN, INC. v. L'ENFANT PLAZA PROP.

Nos. 12462, 12642.

402 A.2d 1222 (1979)

JOHN McSHAIN, INC., Appellant, v. L'ENFANT PLAZA PROPERTIES, INC., Appellee. L'ENFANT PLAZA PROPERTIES, INC., Appellant, v. JOHN McSHAIN, INC., Appellee.

District of Columbia Court of Appeals.

Decided June 5, 1979.

Attorney(s) appearing for the Case

John F. Mahoney, Jr., Washington, D. C., for appellant in No. 12462 and appellee in No. 12642.

Warren K. Kaplan, Washington, D. C., with whom Stephen G. Burns, Washington, D. C., was on the brief, for appellee in No. 12462 and appellant in No. 12642.

Before KELLY, KERN and GALLAGHER, Associate Judges.

GALLAGHER, Associate Judge:

L'Enfant Plaza Properties, Inc. (L'Enfant) sued John McShain, Inc. (McShain) for damages due to the delay in a construction project occasioned by the defendant's trespass. The trial court entered judgment for L'Enfant in the amount of $291,276.31, plus costs. McShain appeals and L'Enfant cross-appeals.

L'Enfant is a real estate developing company responsible for the construction of the East building of L'Enfant Plaza. The East building...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases