1. Home
  2. Browse Decisions
  3. P.2d
  4. 597 P.2d
  5. 597 P.2d 945 (1979)
 

QUIN BLAIR ENTERPRISES, INC. v. JULIEN CONST. CO.

Nos. 5014, 5015.

597 P.2d 945 (1979)

QUIN BLAIR ENTERPRISES, INC., Appellant (Plaintiff below), v. JULIEN CONSTRUCTION COMPANY, a Wyoming Corporation, and the American Insurance Company, a New Jersey Corporation, Appellees (Defendants below). JULIEN CONSTRUCTION COMPANY, a Wyoming Corporation, and the American Insurance Company, a New Jersey Corporation, Appellants (Defendants below), v. QUIN BLAIR ENTERPRISES, INC., Appellee (Plaintiff below).

Supreme Court of Wyoming.

July 3, 1979.

Attorney(s) appearing for the Case

Tom C. Toner of Redle, Yonkee & Arney, Sheridan, signed the brief for appellant in No. 5014 and appellee in No. 5015. Mr. Toner appeared in oral argument on its behalf.

Ernest J. Goppert, Jr. of Goppert, Day & Olson, Cody, signed the brief and appeared in oral argument on behalf of appellees in No. 5014 and appellants in No. 5015.

Before RAPER, C.J., and McCLINTOCK, THOMAS, ROSE, and ROONEY, JJ.

RAPER, Chief Justice.

The principal questions raised in this appeal concern appropriate damages for delay in completing a building contract, the effect of a contractual provision requiring the contractor to request in writing an extension of time to complete the contract, the effect on other contract remedies of an escrow agreement and a "punch-list" which required the contractor to redo work that was incorrectly or defectively done, and the effect of a failure to...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases