1. Home
  2. Browse Decisions
  3. Wn.2d
  4. 90 Wn.2d
  5. 90 Wn.2d 843 (1978)
 

NELSE MORTENSEN v. GROUP HEALTH

No. 45149.

90 Wn.2d 843 (1978)

586 P.2d 469

NELSE MORTENSEN & CO., INC., ET AL, Petitioners, v. GROUP HEALTH COOPERATIVE OF PUGET SOUND, Respondent.

The Supreme Court of Washington, En Banc.

November 9, 1978.

Attorney(s) appearing for the Case

Oles, Morrison, Rinker, Stanislaw & Ashbaugh, Bruce T. Rinker, Richard M. Stanislaw, Short, Cressman & Cable, and David R. Koopmans, for petitioners.

Houghton, Cluck, Coughlin & Riley, John W. Riley, Jack R. Cluck, William N. Mathias III, and Jay V. White, for respondent.

Herman S. Siqueland and Patrick A. Sullivan on behalf of Associated General Contractors of America, Inc., Slade Gorton, Attorney General, William G. Boland, Assistant, Parker Williams, and Douglas F. Graham, amici curiae.

DOLLIVER, J.

Plaintiffs, prime and subcontractors, brought this action to recover damages caused by delays in the remodeling of and adding to the Group Health Hospital in Seattle. The trial court awarded plaintiffs damages of $614,782.77. The case was appealed to the Court of Appeals, and that court reversed. Nelse Mortensen & Co. v. Group Health Cooperative, 17 Wn.App. 703, 566 P.2d 560

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases