1. Home
  2. Browse Decisions
  3. P.2d
  4. 586 P.2d
  5. 586 P.2d 1024 (1978)
 

JONES v. DON L. GORDON CORP.

No. 5875.

586 P.2d 1024 (1978)

Horace JONES, Plaintiff-Appellant, Cross Appellee, v. DON L. GORDON CORPORATION, Defendant-Appellee, Cross Appellee, and Star Manufacturing Co., Defendant-Appellee, Cross Appellant.

Supreme Court of Hawaii.

November 15, 1978.

Attorney(s) appearing for the Case

Charles R. Kozak, Honolulu, for plaintiff-appellant, cross appellee.

Alan M. Oshima, Honolulu (Raymond S. Iwamoto and Joseph T. Kiefer, Honolulu, on the briefs; Carlsmith, Carlsmith, Wichman & Case, Honolulu, of counsel), for defendant-appellee, cross appellant.

Before RICHARDSON, C.J., and KOBAYASHI, OGATA, MENOR and KIDWELL, JJ.

KIDWELL, Justice.

This action seeks damages for delayed and defective delivery of a steel building fabricated on the mainland and shipped to Hawaii in a disassembled condition. The circuit court granted recovery from the mainland manufacturer and denied recovery from the Hawaii distributor of the building. We reverse as to both defendants.

On July 5, 1972 plaintiff-appellant Jones, a building contractor and developer, contracted with defendant Don L. Gordon...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases