1. Home
  2. Browse Decisions
  3. Ill.
  4. 46 Ill.
  5. 46 Ill. App.3d 873 (1977)
 

LOUGHMAN CABINET CO. v. C. IBER & SONS

No. 76-94.

46 Ill. App.3d 873 (1977)

361 N.E.2d 379

LOUGHMAN CABINET CO., Plaintiff-Appellant, v. C. IBER & SONS, INC., Defendant-Appellee.

Appellate Court of Illinois — Third District.

Opinion filed March 31, 1977.

Attorney(s) appearing for the Case

Tim Swain, II, of Swain, Johnson and Gard, of Peoria, for appellant.

John C. Mulgrew, Jr., of Davis and Morgan, of Peoria, for appellee.

Order affirmed.

Mr. PRESIDING JUSTICE STENGEL delivered the opinion of the court:

Plaintiff, Loughman Cabinet Company, a subcontractor for millwork, brought this action to recover damages for construction delays against defendant Iber & Sons, Inc., the general contractor for three new buildings at Illinois Central College in East Peoria, Illinois. Plaintiff sought recovery of $49,935.35 in increased costs incurred as a result of delays allegedly caused...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases