1. Home
  2. Browse Decisions
  3. Pa.Commw.
  4. 7 Pa.Commw.
  5. 7 Pa.Commw. 71 (1973)
 

ALGER-RAU & ASSOC., INC. v. GEN. STATE AUTH.

Appeal, No. 700 C.D. 1972.

7 Pa.Commw. 71 (1973)

Alger-Rau & Associates, Inc. v. General State Authority.

Commonwealth Court of Pennsylvania.

January 9, 1973.

Attorney(s) appearing for the Case

Norman I. White, with him Edward C. First, Jr., and McNees, Wallace & Nurick, for appellant.

John A. Alogna, Assistant Counsel, with him H.E. Cardoni, Assistant General Counsel, and Michael A. Madar, General Counsel, for appellee.

Argued December 5, 1972, before President Judge BOWMAN and Judges CRUMISH, JR., KRAMER, WILKINSON, JR., MENCER, ROGERS and BLATT.

OPINION BY JUDGE ROGERS, January 9, 1973:

Alger-Rau & Associates, Inc., the general contractor of a building for the Commonwealth, has appealed from a decision of the Board of Arbitration and Claims dismissing its claim for expenses occasioned by delay of the work. The delay was caused by the failure of the subsoil at the site to support specified load tests, ultimately cured by the installation of additional footings.

The Commonwealth has moved to quash...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases