1. Home
  2. Browse Decisions
  3. A.3d
  4. 96 A.3d
  5. 96 A.3d 477 (2014)
 

C AND H ELEC., INC. v. TOWN OF BETHEL

No. 19162.

96 A.3d 477 (2014)

312 Conn. 843

C AND H ELECTRIC, INC. v. TOWN OF BETHEL.

Supreme Court of Connecticut.

Decided August 5, 2014.

Attorney(s) appearing for the Case

Jeffrey J. White , Hartford, with whom, on the brief, were Gregory R. Faulkner , Hartford, and Elizabeth K. Wright , for the appellant (plaintiff).

Benjamin B. Manchak , with whom were Joshua A. Hawks-Ladds and, on the brief, Richard C. Robinson , Hartford, for the appellee (defendant).

ROBINSON, J.

This appeal requires us to consider whether a property owner's conduct constituted "active interference" for purposes of an exception to a "no damages for delay" clause in a construction contract, which otherwise would preclude a contractor from recovering additional costs for delays caused by the owner, instead giving a contractor additional time to complete the job. The plaintiff, C & H Electric, Inc., appeals...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases