1. Home
  2. Browse Decisions
  3. P.3d
  4. 28 P.3d
  5. 28 P.3d 669 (2001)
 

SME INDUS., INC. v. THOMPSON, VENTULETT, STAINBACK & ASSOCS.

No. 990869.

28 P.3d 669 (2001)

2001 UT 54

SME INDUSTRIES, INC., a Utah corporation, Plaintiff and Appellant, v. THOMPSON, VENTULETT, STAINBACK AND ASSOCIATES, INC.; Robert Norman Veale; Gillies, Stransky, Brems & Smith; Jonathan Bradshaw; Reaveley Engineers & Associates, Inc., a corporation; Earl S. Eppich; and Does 1-40 inclusive, Defendants and Appellees.

Supreme Court of Utah.

Rehearing Denied July 26, 2001.

Attorney(s) appearing for the Case

Harold C. Verhaaren, D. Scott Crook, Salt Lake City, for plaintiff.

John N. Braithwaite, Salt Lake City, for TVSA defendants.

Craig R. Mariger, Edward R. Munson, Salt Lake City, for GSBS defendants.

Craig C. Coburn, Bastiaan K. Coebergh, Salt Lake City, for Reaveley defendants.

RUSSON, Associate Chief Justice:

¶ 1 Plaintiff SME Industries, Inc., brought this action against numerous defendants, seeking delay damages and other economic losses it allegedly incurred while working on a construction project. The trial court granted defendants' motions for summary judgment, and SME appeals.

BACKGROUND

¶ 2 On May 20, 1992, Salt Lake County (the "County") entered into a contract for architectural and consulting services...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases