1. Home
  2. Browse Decisions
  3. Ill.
  4. 65 Ill.
  5. 65 Ill. App.3d 480 (1978)
 

PATHMAN CONSTR. CO. v. HI-WAY ELECTRIC CO.

No. 76-776.

65 Ill. App.3d 480 (1978)

382 N.E.2d 453

PATHMAN CONSTRUCTION CO., Plaintiff and Counterdefendant-Appellee, v. HI-WAY ELECTRIC CO., Defendant and Counterplaintiff-Appellant. — (THE HOME INDEMNITY COMPANY, Counterdefendant-Appellee.)

Appellate Court of Illinois — First District (4th Division).

Opinion filed October 12, 1978.

Attorney(s) appearing for the Case

Vihon, Fuchs, Temple & Berman, Ltd., and Edward R. Nathanson, both of Chicago (Robert F. Fuchs, Harvey Berman, and John Roselli, of counsel), for appellant.

Hoffman & Davis, of Chicago (Sol A. Hoffman and Alvin L. Kruse, of counsel), for appellees.

Judgment affirmed.

Mr. JUSTICE LINN delivered the opinion of the court:

This is an action for damages sustained by plaintiff, Pathman Construction Co. (Pathman), allegedly due to the delay of defendant, Hi-way Electric Co. (Hi-way), in performing its work under an electrical subcontract agreement. After a bench trial in the circuit court of Cook County, the trial court entered judgment for plaintiff in the amount of $92,583.93. In a supplemental order the...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases