BROCK & BLEVINS COMPANY v. UNITED STATES

No. 292-59.

343 F.2d 951 (1965)

BROCK & BLEVINS COMPANY, Inc. v. The UNITED STATES.

United States Court of Claims.

April 16, 1965.


Attorney(s) appearing for the Case

Gaines V. Palmes, Washington, D. C., for plaintiff.

John R. Franklin, Washington, D. C., with whom was Asst. Atty. Gen., John W. Douglas for defendant.

Before COWEN, Chief Judge, and LARAMORE, DURFEE, DAVIS and COLLINS, Judges.


DURFEE, Judge.

This is a suit to recover damages for delays due to the fault of the Government arising out of a subcontract (later assigned to the Department of the Army), entered into by plaintiff with the prime contractor, Hiwassee Constructors on October 27, 1952. The subcontract covered rehabilitation of piping, mechanical and electrical equipment of the North Acid area of the Volunteer Ordnance Works at Chattanooga, Tennessee.

Plaintiff claims damages...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases