OLD COLONY CONST., LLC v. TOWN OF SOUTHINGTON

No. 19346.

113 A.3d 406 (2015)

316 Conn. 202

OLD COLONY CONSTRUCTION, LLC v. TOWN OF SOUTHINGTON.

Supreme Court of Connecticut.

Decided April 21, 2015.


Attorney(s) appearing for the Case

Jared Cohane , with whom were Peter J. Martin and Luke R. Conrad , and, on the brief, Timothy T. Corey , Hartford, for the appellant (plaintiff).

Linda L. Morkan , with whom were Dennis C. Cavanaugh , and, on the brief, Ryan M. Burns , Hartford, for the appellee (defendant).

Wendy Kennedy Venoit and Peter J. Zarella , Hartford, filed a brief for the Connecticut Associated Builders and Contractors, Inc., as amicus curiae.

PALMER, EVELEIGH, McDONALD, ROBINSON and PRESCOTT, Js.


This appeal principally concerns a municipality's ability to recover liquidated damages for a contractor's failure to timely complete a public works contract if the municipality has elected to terminate the contract for convenience1 or has contributed to some portion of the delay. The plaintiff, Old Colony...

Let's get started

Leagle.com

Welcome to the leading source of independent legal reporting
Sign on now to see your case.
Or view more than 10 million decisions and orders.

  • Updated daily.
  • Uncompromising quality.
  • Complete, Accurate, Current.

Listed below are the cases that are cited in this Featured Case. Click the citation to see the full text of the cited case. Citations are also linked in the body of the Featured Case.

Cited Cases

  • No Cases Found

Listed below are those cases in which this Featured Case is cited. Click on the case name to see the full text of the citing case.

Citing Cases